DELHI DEVELOPMENT AUTHORITY
NORTHERN  DIVISION NO.10

LIST OF VARIOUS ACTIVITIES

1.	Details of Pending Final Bills and Non – refund of Security Deposits. 

Details of Pending Final Bills for the Month Ending  August, 2007.

Sl. No.	Name of Work	Agency	Agreement No.	Stipulated date of start / completion	Actual date of completion	Date of Payment of Final Bill	Reasons for delay in payment of Final Bill.	

------	
---------------------------------------------------------------
	
Nil ---------------	
----------------	
--------------	
--------------	
-------------	
---------------	

2.	Present Status of Works 
List of works costing more than Rs.2.00 Lacs as on August, 2007

S. No.	Name of work 	Agency 	Estt. Cost/ Tendered Amt. (in Lacs) 	Stipulated date of Start/ Completion 	Physical Progress 	Actual Date of Completion 	Remarks 	
1.	D/o Golf course at Bhalswa 
SH.: D/o water bodies & other misc. work.
M/s Bajrang Engineering 
	M/sBajrang Engineering	4.77/3.01	26.07.07/
28.09.07	75%	In progress		
2.	D/o Major Dhyan Chand Sports Complex 
SH: Raising of Boundary Wall 
	M/s Panchal Construction Co. 	6.61/ 9.105 	30.04.07/ 
29.06.07	100%	In Progress 		

3.	Protection of Vacant land under N.Z.
S.H. C/o Boundary wall with SFRC railing at Satywati Colony.(Running Contract)  
	Sh. Rakesh Kumar	         / 11.90	7.12.06/
06.09.07	100%	In Progress 		
4.	D/o Land in Green area at Jahangir Puri Bralswa.
SH.: C/o Boundary wall around green area.
	M/s Birendra Construction Co. 	41.31/ 39.70 	03.06.07/ 
02.11.07	80%	In Progress 		
5.	C/o170 MIG (Incremental) Houses B-4 at Narela 	M/s A.K. Mehta & Co.
	443/385	23.11.02/ 
22.05.04	86%	In Progress 

		
6.	Protection of DDA Land under North Zone 
	Yespal Singh 	7.96/8.33	05-08-04/
04-11-07	5%	In Progress		
7.	D/o Golf Course at Bhalswa 
SH: Filling of sandy soil in fair way No. 5 	M/s Raj Builders 	4.67/9.97	23-08-07/
07-10-07	10%	In Progress		

3. 	Projects held up due to Court Case 			:	N/A
	………….. Respective Court with Case No.		:	N/A 
	………….. Date  of Next Hearing 			:	N/A 
4.	Rain Water Harvesting 
	Already provided 						: 	N/A
	Proposed 							:	N/A

5.	Water Bodies : 
	………. Identified, status and under 			:	 
Encroachment 							One water body K block Janhangir puri, partly encroached, 
Drg. Awaited. 
										One no. at Siraspur Identified. 
6.	Details of Deposit Works: 
	(a)	In hand 						:	N/A
	(b) 	Under approval 					:	N/A
	(c)	Status 						:	N/A

7.	Detail Deviation in works: 
7.	(a) …….. Undertaken 

S. No.	Name of work/ Agency 	Tendered Cost 
(Rs.)	Amount of Deviation 
(Rs.)	%age of Deviation 	
1.		Protection of vacant Land under North Zone 
SH: C/o Boundary wall around vacant land behind Ramgarh, Jahangirpuri. 
 	14,29,475.00	7,33,000.00	52% (Approx)	
2.		C/o 170 MIG houses (incremental) at B-4 Narela
	3,85,37,878.00	5,00,000.00
(Approx.)	1.30%

7. 	(b)… Proposed (in Principal approval) 	:	N/A

8.	Restricted Call of Tender 			:	N/A 

9.	Rescinded Works : 
Details of Rescinded Works – Status as on August, 2007

Sl.
No.	Name of Work	Agency	Agmt. No.	Stipulated Date of Start/ Completion	Provisional extension granted upto	Date of rescission of work	Date of Award of Balance Work	Remarks	
1	2	3	4	5	6	7	8	9	

-----
	
Nil 	
-------	
-------	
----------	
------------	
-------	
---------	
--------	

10. 	Arbitration & Related Court Cases 
	(a) 	Pending Arbitration Case as on August, 2007

Sl. No.	Name of work / Agreement No. / Agency	Arbitrator	Present Position	Next date of Hearing	Remarks	

----
	
----------------Nil ---------------------------
	
-------------	
----------------------	
------------------	
---------------	

10. (b) (i) Court Case. 
Details of Court Cases Pending at the end of August,  2007- Service Matters.

Sl. No.	File No.	Name of Employee	Name of Court/ Suit No.	Name of Panel Lawyer	Nature of Case	Present Position	Next date of Hearing	Remarks	

----	
---------------
	
--------Nil ----------	
--------------------------------	
----------	
----------	
-----------------------	
-----------	
-----------	

10. (b) (ii) Court Case. 
Details of Court Cases Pending at the end of August,  2007- (Works)

S. No.	Case Title / Party Name  	File No.	Suit No./ Name of Court 	Name of the Division 	Name of P/L	Date of Entrustment of P/L	Last date of Hearing 	Next date of hearing 	Status of the case. 	
1.		C/o C & C Gulabi Bagh
DDA Vs M/s Kumar Constn.Co. 9/6686 Street  No.8, Dev Nagar, New Delhi 
	F.21 (291)  / 06 /H.C./ Legal	-	ND-10	Sh. Gauran Sareen 	-	-	09-01-09	Case to be admitted in the H.C.	
2.		C/o 144 SFS house Cat. III i/c water supply in Narela M/s K. R. Builders (P) Ltd. Vs. DDA
	F-21 (33) /03/HC/Legal	142/2003 High Court 	ND-10	Sh. Gaurav Sareen  
24643342
9810533717	-	-	10-09-07	Final Judgment is awaited from the Court 	
3.		LSC at Ashok Vihar, Ph.III, Pkt. B 
DDA V/s J. C. Khanna & Sons.	F-21 (117)97/HC / Legal 	808 / 1997 / H/ C	ND-10	Ms. Ansuya Salwan 
9811225368
25814176-6483	-	-	11-10-07	-	
4.		C/o C & C at Gulabi Bagh 
DDA V/s M/s Kumar Const. Co.
	F-2(18)98 /TC/ Legal	981/2006 T/H Court	 ND-10	Harjeet Kaur 
23914113	-	-	10-12-07	Further Proceeding 	
5.		C/o104 SFS Houses Cat.II at Shalimar Bagh Pkt.D, Pkt.A, Ph. IV, S.H: Providing and installation cast in situnder reamed pile foundation i/c grade beams under agreement No.  29/EE/ ND-10- M/s Aadhar Stumbh Vs DDA (New Case.)	F-5(62) 04/TC/Legal	88/2005 T/C 	ND-10	Mr. Zulfiqar 
9811480141	-	-	15-11-07	-	

S. No.	Case Title / Party Name  	File No.	Suit No./ Name of Court 	Name of the Division 	Name of P/L	Date of Entrustment of P/L	Last date of Hearing 	Next date of hearing 	Status of the case. 	
6.		M/o Completed Schee (NZ) SH: C/o Road  for area cleared after demolition of Satyawati Nagar M/s Dharamvir Vs DDA. 
	F-11 (65) 04/Arbn /TC/ Legal	312/2006 Tis Hazari 	ND-10	Smt. Harjeet Kaur
23914113	---	--	20-11-07	For further proceedings. 	
7.		C/o 560 SFS houses at Shalimar Bagh Blk.C & D.
SH: C/o 208 SFS House Gr. II, under reames pile foundation i/c grade beam M/s Caneer Constn. Vs. DDA. 
	F 5(62)04 / TC/ Legal 	223/2004 Tis Hazari 	ND-10	Smt. Harjeet Kaur
23914113	----------	---------	17-10-2007	For further proceedings.	
8.		C/o 112 LIG Houses, 16 Shops and 20 MIG Houses at Ashok Nagar along Faiz Road, Delhi 
M/s Caneer Constn. Vs. DDA.
	F-11 (32)05/ TC/ Legal	174 / 2005 Tis Hazari 	ND-10	Sh. S.M. Zulfiqar Gar Alam 	-----------	----------	30-11-07	For further proceedings.	
9.		Kumar Constn. V/s DDA (New Case)
	F21 (133)07/ HC/ Legal 	High Court 	ND-10	Ajay Verma Standing Council	----------	------------	30-10-2007	Appeal filed 	
10.		RHPVS DDA 	Court Case 	------------	ND-10	Sh. Bhupesh Narula 	----------	-----------	-------	To be discussed with Panel Lawyer 	
11.		Atma Ram Dogra Vs. UOI 	F2 (390) 06/HC/Legal 	High Court 	ND-10	Sh. Gaurav Sareen 
981033717	---------	-----------	07-02-08	-------	

12.		Wazirpur Industrial Area Vs. UOI 	F-12 (515) 07 / HC / Legal 	High Court 	ND-10	Sh. Rajeev Bansal 	---------	-----------	--------	------------	

11.	Detail of Q.C. Lab. Tests, Procedure 					:	N/A 

12.	Fire Fighting Equipments 						:	N/A
(Installed with locations)

13.	List of Soil Testing Laboratories 					:	N/A

14.	List of Approved Structural Consultant 				:	N/A

15.	Technical Circular 							:	Available 

16.	Q.C. Circular 								:	Available 

17.	List of Contractors A, B, C, D Categories				:	N/A 

18.	R/S/EIS/EOT Cases and Completion Certificate. 

18. (a) 	Details of EIS Pending as on  August, 2007.

S. No.	Name of Work 	Name of Agency 	Amount (in Lacs)	W.e.f.	
1.	C/o 560 SFS houses &  420 S/G at Pkt.I, Block C &D at Shalimar Bagh 
SH: C/o 192 SFS houses &  144 SIG in Gr. I,
EIS No. 2
	M/s A. K. Mehta & Co. 	1.09	30-07-2007	
2.	C/o 560 SFS houses &  420 S/G at Pkt.I, Block C &D at Shalimar Bagh 
SH: C/o 192 SFS houses &  144 SIG in Gr. I,
EIS No. 3
	M/s A. K. Mehta & Co.	0.512	30-07-2007	

3.	C/o 560 SFS Houses &420 S/G at Pkt. I Block C & D at Shalimar Bagh 
SH: C/o208 SFS houses Cat. II & 156 S/G in Gr. II 
EIS No.2
	M/s A. K. Mehta & Co.	1.26	30.07-2007

18. (b) 	Details of RIS /DIS Pending as on August, 2007

S. No.	Name of Work	Name of Agency	W.E.F.	

1.
	
-------------------------Nil --------------------------------------	
------------------Nil------------------	
----------Nil ------	

18. (c) Details of EOT as on August, 2007.

S. No.	Name of Work	Name of Agency	W.E.F.	

-------
	
-----------------------Nil ----------------------------	
------------------------------	
----------------------------------	

18. 	(d) Completion Certificate: 					:	NA

19.	List of approved rates of SE (P) 				:	Available 

20.	Areas where services are handed over to 			:
	MCD, DJB and Deficiency Charges. 

Present Status of Services as on August 2007.

S. 
No.	Name of Areas/ Colony	Date of  Handed over the services	Deficiency Charges 	Remarks	
		Code No. 	Road & SW Drain 	Water Supply 	Sewerage 			
1.

	C.S.C. at Block A , Ashok Vihar 
Ph. III, 	NZ 94-10-65	07-02-2001	-	07-02-2001			

2.	CSC at Block A , Ashok Vihar  Phase IV 	NZ -93-10-30	31-08-2000	02-08-2000	07-02-2001	
		
3.	CSC at Ashok Vihar, Ph. Blk. B & C
	NZ-93-10-31	27-02-2001	17-02-2001	28-02-2001			
4.	CSC at Gulabi Bagh 	NZ-93-10-28	18-09-2000	22-01-2001	08-02-2001
			
5.	Community Centre at Ashok Vihar Ph.I (Central Market) 
	NZ-93-10-34	01-03-2001	Under process of handing over  	28-02-2001		File for land charges of c/o UGR Submitted to VC/DDA	
6.	Community Centre at Wazirpur Industrial Area 	NZ-93-10-32	19-03-2001	Under process of handing over  	02-03-2001		Permission for Road Cutting Regarding Water Supply connection is awaited 	
7.	CSC Wazirpur Ph.III Harigen Colony 
	NZ-93-10-67	20-03-2001	-	07-02-2001			
8.	CSC Block A Ashok Vihar Phase-I	NZ-93-10-55	31-08-2000	02-08-2000	28-09-2000			
9.	CSC at Blk. B, Ph.I, Ashok Vihar 	NZ-94-10-56	27-02-2001	17-02-2001	28-02-2001			
10.	CSC Blk. –KD Ashok Vihar
Ph-I,	NZ-94-10-57	27-02-2001	30-01-2001	28-02-2001			
11.	CSC Blk D, Ashok Vihar 
Phase I	NZ-94-10-58	31-08-2000	02-08-2000	29-9-2000			
12.	CSC Block I , Ashok vihar PhaseI 	NZ-94-10-59	27-02-2001	17-02-2001	28-02-2001			
13.	CSC Pkt. B, Ashok Vihar Phase II	NZ-94-10-60	31-08-2000	02-08-2000	28-09-2000			
14.	CSC at Blk. G Ashok Vihar Phase I 	NZ-94-10-61	31-01-2001	02-08-2000	07-02-2001			
15.	CSC Pkt. A Ashok Vihar Phase II 	NZ-94-10-62	31-08-2000	02-08-2000	28-09-2000			

16.	CSC Blk. B2 Ashok Vihar Phase II
	NZ-94-10-63	19-03-2001	02-08-2000	28-09-2000			
17.	CSC Blk. C1 Ashok Vihar Phase II 
	NZ-94-10-64	31-08-2000	02-08-2000	28-09-2000			
18.	CSC at Ashok Vihar Phase III Sashit Nagar Extn. 
	NZ-94-10-68	27-02-2001	30-01-2001	28-02-2001			
19.	LSC at Block H Ashok Vihar PhaseI 
	NZ-94-10-54	26-02-2001	17-02-2001	28-02-2002			
20.	LSC at Block J Ashok Vihar PhaseI
	NZ-93-10-37	19-03-2001	17-02-2001	28-02-2001			
21.	LSC at Gujrawalan Phase-I 	NZ-01-10-05	17-07-2004	20-12-2005	Handed over to DJB
			
22.	LSC at Gulabi Bagh 	NZ-01-10-07	17-07-2004	Under process of Hading over 	Under process of handing over
 		The deficiency estimate for water supply have been received. 	
23.	LSC at Ashok Vihar Phase III (Near MCD Engg. Society) 	NZ-01-10-06	20-07-2004	Under process of Hading over 	Under process of handing over 		Water supply line laid, connection has not been provided as the scheme was approved by DJB with condition that DDA will provide tube well 	
24.	LSC No.2 Ashok Vihar Phase II (Fly over market)
	NZ-93-10-36	01-03-2001	17-02-2001	28-02-2001			
25.	LSC No. 1 Ashok Vihar Phase II (Pragati Market )
	NZ-93-10-35	01-03-2001	17-02-2001	28-02-2001			

26.	LSC Blk. B, Ashok Vihar Phase III	NZ-01-10-006	20-07-2004	Under process of handing over 	Handing over to DJB		Amount of Deficiency charges mutually agreed is to be paid to DJB. Services handed over.
	
27.	LSC E & V Market Lawrence Road at B-4. 	NZ-01-10-014	-	-	-		To be handed over in next lot as per EE (HQ)/SE (P) –III intimated to EE (P) I /SE(P) –IV/ SEZ vide letter  No. F-1 (31) EE (HQ) SE (P)/01/NZ /620 dt. 04-10-02 that the development work of this area is in progress and completion not submitted to MCD/ DJB. Now all the services has already been laid.  	
28.	Satyawati Nagar in Wazirpur Res. Ph.III
	NZ-93-10-92	31-01-2001	03-08-2000	23-10-2000			
29.	SW Drain at Ashok Vihar PhaseIII 	NZ-93-10-04	28-06-2000 (S.W. drain only) 	-	-			
30.	Satyati Nagar  in Wazirpur Res. Ph.III 
	NZ-94-10-91	31-01-2001	31-08-2000	23-10-2000			

21. (a) Details of Houses as on August, 2007

Sl. No. 	Name of Scheme 	Year of Comp. 	Divn. 	Houses Constructed	Total Allotted/ Handed over	Total Vacant	Specified Number of Vacant Houses	
				SFS 	MIG	LIG	Janta 	Total 	SFS 	MIG	LIG	Janta 	Total 	SFS 	MIG	LIG	Janta 	Total 		
1.	960 Janta Dues Pkt. B, Lawrance Road   
	1988	ND-10				960	960				959	959			1	1	1	208 T.F.	
2.	96/ 104 – SFS Cat II, Bl.D. Pkt. A, Shalimar Bagh. 
	2003	ND-10	104				104	100				1000	4				4	422 T.F.,  439 S.F., 384 T.F., & 428 T.F. 	
3.	180 SFS Houses at Ashok Vihar Phase-III 
(Shakti Aptts.) 
	1988	ND-10	180				180	179				179	1				1	88 T.F.	
4.	656/ 672 LIG Houses at Jahangirpuri 
	1989	ND-10			672		672			666					6		6	8, 28, 318, 320, 428, &  621	
5.	32 LIG at Jahangipuri 
	2000				32		32			29					1		1	686 SF	
6.	188 MIG/ LIG & Scooter garages at Pkt. B, Ashok Vihar Ph-III 	1996					188 (S.G.)	188
(S.G)				150
(S.G.)	150
(S.G.)				38 
(S.G.)	38
(S.G.)	Bl. 2 : 1 to 8 = 	8 Nos.
Bl. 3 :9 = 	1 No.
Bl. 5 : 10 = 	1 No.
Bl. 6 : 11 to 19 =	9 Nos. 
Bl. 8: 20 to 24 =	5 Nos.
Bl. 9: 25 to 30 = 	6 Nos.
Bl. 11: 31 to 34 =	4 Nos.
Bl. 13 : 35 to  38 =4 Nos. 
Total: 		 38 Nos.	
7.	Janta House C-6, Lawrance Road
																1	1	147C  T.F.	

8.	C/o 192 SFS Houses Gr.I & 144 S/G at Bl.
C &D , Shalimarbagh	2006	ND-10	192				192	111				111	81				81	G.F.:  5, 9, 13, 17, 21, 25, 29,  37, 41,  49, 53, 57,  71,  85, 93, 97,  113,  129,  145,  161,  173, 177, 181, 189 =24 Nos. 

F.F.: 10,  38, 46, 50,  82,  98, 102,  118, 122, 126, 130,  138, 142,  154,  178, 182, 186, 
 =17 Nos.

S.F.:  7,   15, 23,  47,   67, 71,  83,  91, 95,  111,  131, 135, 139, 147, 159,  175, 183, 187
= 18 Nos.

T.F.: 4,  20, 24, 32, 40, 44, 52, 56, 60, 80, 92, 100,  120,  128, 132, 136, 140, 144, 152, 164, 184, 188 = 22 Nos.
 
Total:  24+17+18+22 
=81 Nos. 
	
9.	C/o 208 SFS Houses Gr. II & 156 S/G at Bl.
C&D, Shalimarbagh	2006	ND-10	208				208	92				92	116				116	GF: 193, 209,  217, 221, 233, 237,  253,  265,   277,  281,       301,  305,   313,   329,  333,   345,   357,  361,   373,  377, 382,  385,  389  = 23 Nos.

F.F. :   202,   218, 222, 226,   234, 242,  250,  258,   274,  282,  286, 290,   302, 306, 310, 314,  318, 322,  326, 330,  338, 346, 350, 358,  370,  382,  386, 390, 394 = 29 Nos. 

S.F. :   203,  207,  211,  215, 223,  235,   247,   267,  271,  275,  279,   287,   295,  303,  311,  315,  319,  323,  327,  331,  335,  339,  351,  355,   363,  367, 375,  379, 383, 387, 391,   399 = 32 Nos.

T.F.:  196,  204,  212,  228,  232,  240, 248, 252, 256, 260,  264, 268,  280,  284,  288,  296, 300, 304,  316,   328,  332,  336,   344, 348,  358, 360, 364, 368, 376,  380,  392, 396 = 32 Nos. 

Total:  23 + 29 + 32 + 32 
= 116 Nos. 	

21. (b)  Details of Vacant Commercial Properties as on August, 2007.

Sl. No. 	Name of Scheme 	LSC/
CSC	Divn. 	Blk/ Pkt.	Year / Comp 	Constructed	Vacant	Specific No. of Vacant Shops	
						Shops 	Stall 	VPF	Office 	Kiosk 	Shops 	Stall 	VPF	Office 	Kiosk 		
1.	Ashok Vihar Phase-I 	LSC 	ND-10	H		5					1					Shops:23 (GF) 	
2.	Ashok Vihar Phase-I	LSC	ND-10	J		47					1					6A (GF)	
3.	Ashok Vihar Phase-I (Near Engg. Society)	CSC	ND-10		1993	13					2					Shops : 5 & 8 (G.F.) 	
4.	Ashok Vihar Phase-III, 	LSC	ND-10	B	1999	67	8		24					1		Office: (S.F.) : 205	
5.	Ashok Vihar Phase-III,  (Near MCD Engg. Society) 	LSC	ND-10		1999	15		17			4		16			Shops: 2, 4,  11, 14 = 4 Nos.
VPF : 1, 2, 3, 4 , 5, 6, 7, 8, 9, 10, 11, 12, 13 , 14, 15 , &  16. = 16 Nos.	
6.	Ashok Vihar Phase-IV 	CSC	ND-10	A	1991	20			4		2					Shops:  5 & 16 (G.F.)	
7.	Ashok Vihar Phase-IV	CSC	ND-10	B & C	1992	14			6		2					Shops: 6 &  14 (G.F.) 	
8.	Gulabi Bagh 	CSC 	ND-10	Engg. Society 	1992	24			8		2			1		Shops: 5 & 15 
Office:  31  (SF.)
	
9.	Gujranwala 
	LSC 	ND-10		1999	11	10				1	8				Shops:  (GF) 22
Open Stall : 1, 2, 3, 4, 6, 7, 8 &  9. 
	
10.	Lawrence Road, Near DTC Bus Stand	CSC	ND-10	B-4	1991	25	7		4		1			2	1	Bank:  1 No. 
Post Office :  1 No.
Klosk :  1 No. 	

11.	Jahangir Puri 	CSC 	ND-10			30 Nos.			2 Nos.		13 Nos.			2 Nos.		Shops: 5, 6, 9, 11, 13, 16, 19, 24, 26, 27, 28, 29, 30, = 13 Nos.
Offices: 31, 32  = 2 Nos.
Office are temporarily occupied by Hort. Div.  No.10	
12.	Lawrence Road	LSC 	ND-10	C-7	1989	18	15		2		5	3		1		Shops: 17, 34, 35, 46& 48 = 5 Nos.
Stalls: 23, 41, &  43 = 3 Nos.
Offices: 1 No. (FF)
	
13.	Lawrence Road 	LSC	ND-10	B-4	1992	74		14			14		4			Shops: GF:  7, 12, 18, 19, 22, 28, 30, 32, 35, 39 = 10 Nos. 
(F.F.) 8, 15, 24, & 32 = 4 Nos. 
Open Stall : 4, 5 ,  9, 14 = 4 Nos. 	

21 (c) Details of Vacant Commercial Plot as on August, 2007

S. No.	Circle/ Division 	Name of Scheme/ Location of Plot	Specific No. of Plot	Plot Details	Whether demarcated or not	Position of Service if not available	Remarks	
				No.	Land Used 	Area in Sq.m.				
1.		CC12/ ND-10	Ashok Vihar Phase-IV, (Bleaching Ground) at weavers Colony) 	-	1 No. 	Commercial 	860 M2 (Approx.)	Fenced 	-	-	
2.		CC12/ ND-10	Ashok Vihar Phase-IV, (Weavers Colony)	-	1 No.	Institutional 	4000 M2
(Approx.)	Fenced 	-	-	
3.		CC12/ ND-10	Ashok Vihar Phase-IV, (Near ESS Weavers Colony) 	-	1 No.	Religious 	360 M2
(Approx.)	Fenced 	-	-	
4.		CC12/ ND-10	Lawrence Road 
(Near B4 LSC Market)	-	1 No 	Commercial	7200 M2
(Approx.)	Fenced 	-	-	
5.		CC12/ ND-10	Lawrence Road
(Near Police Station, CC) 	-	1 No.	Commercial	21500 M2
(Approx.)	Fenced 	-	-	
6.		CC12/ ND-10	Printing Press Area at Lawrence Road 	i) 3 &4

ii) -	i) 2 Nos. 

ii) 1 No.	Commercial 

Commercial	945 M2
(each.)
2712 M2
	Fenced 

Fenced 	-	-	

7.		CC12/ ND-10	LSC B-4, Lawrence Road	i) 1,4,6, 7, 8

ii) 2 &3 

iii) -	5 Nos.

2 Nos.

1 No.	Commercial

Commercial

Commercial 	i) 180 M2
(each)
ii) 135 M2
(each)
iii) 4000 M2
	Fenced 	-	2746.22sq.m. Allotted out of  4000sq.m.	
8.		CC12/ ND-10	Lawrence Road B-4, Near Tyagi  Public School 	-	2 Nos.	Commercial	i) 7797 M2
ii) 1650 M2
	Fenced 	-	-	
9.		CC12/ ND-10	C.C. at Lawrence Road (Residential Area) 	i) 1 , 2, & 3

ii) 4
iii) 5
iv) 6
v) 12	i) 3 Nos.

ii) 1 No.
iii) 1 No.
iv) 1 No.
v) 1 No.	

Commercial 	i) 162 M2
(each.)
ii) 670.50 M2
iii) 882 M2
iv) 540 M2
v) 1650 M2

Fenced 	-	-	
10.		CC12/ ND-10	C.C. at Lawrence Road (Residential Area) 
	i)  2
ii) 24	i) 1 No.
ii) 1 No.	Commercial 	i) 1591 M2
ii) 160 M2
	Fenced 
Not fenced 	-	-
Encroached  by Jhuggies 	
11.		CC12/ ND-10	Lawrence Road
(Industrial Area)	G-1 B-23
G-1 B-49
G-37/5

C-18/A
C-40/1 & C40/2
A/19A	1No.
1No
1No

1No
2 Nos.
1No.	

Industrial 

	400 M2
300 M2
5600 M2

5600 M2
1779 M2
4800 M2	Fenced 
Not Fenced
Not Fenced

Fenced
Fenced 
Fenced	-	-
Encroached  by Jhuggies
Encroached by Temple Akhara & MCD Store 

-	

12.		CC12/ ND-10
	LSC  at pocket C7 Lawrence Road	6	1No.	Commercial 	107 M2	Fenced 	-	-	
13.		CC12/ ND-10
	C.C. at G.T. Karnal Road	Plot B	1 No.	Commercial 	2450 M2
	Fenced 	-	-	
14.		CC12/ ND-10	L.S.C. at B – Block Ashok Vihar Phase-III.	-	1 No.	Commercial 	167 M2
	Fenced 	-	-	

21. (d) Details of Vacant Residential Plot as on August, 2007

S. No.	Circle	Name of Scheme/ Location of Plot	Specific No. of Plot	Plot Detail	Whether Demarcated or not	Position of Service is not available	Remarks	
				No.	Size of Plot	Area in Sq.m.				

---
	
---	
-----------Nil---------------	
------------	
-----------	
----------	
-----------	
------------	
-----------	
----------	

22. 	Jurisdiction of CE/ Map. EE wise 			:	…………………………………………………………………………………………………

23.	Details of land handed over to Engineering 		:	Nil 
	Wing for Development. 

24.	Position of Regular Staff 				:

S. No.	Designation 	Sanction Strength 	Men in Position  	Vacant Position 	
1.		Executive Engineer 	1	1	Nil 	
2.		Asstt. Engineer 	5	5	Nil 	
3.		Junior Engineer 	13	14		

4.		Asstt. Account Officer 	1	1	Nil 	
5.		Head Clerk 	1	Nil 	1	
6.		Steno 	1	1	Nil 	
7.		U.D.C. 	4	4	Nil 	
8.		D/ Man Gr. -II 	1	1	Nil 	
9.		L.D.C.	6	2	4	
10.		Driver	1	1	Nil 	
11.		Peon 	4	4	Nil 	
12.		Security Guard 		3 (R) +11W/C (R)=14		
13.		Daftary	1	1	Nil 	
14.		Beldar 		2 (R) + 7 W/C (R) =9		
15.		Mason 		4 W/C (R) 		
16.		Env. Asstt. 		1 (R)		
17.		Sanitary Mate. 		NIL 		
18.		Asst. Supervisor 		1 (R)		
19.		Mate 		2 (R)+ 14 W/C (R) =16		
20.		Fitter 		1(R)+2 W/C (R) = 3		
21.		Wire Man 		1 W/C(R) 		

S. No.	Designation 	Sanction Strength 	Men in Position  	Vacant Position 	
22.		Carpenter 		1 (R)		
23.		Coolie 		5 W/C (R)		
24.		Helper 		1 W/C (R)		
25.		Asst. Typist 		1  W/C (R)		
26.		Khalasi 		8 W/C (R)